AG 2010 06 21 - Laserfiche WebLink

Home Browse Search

STA'CE OF NORTH CAROLINA CABARRUSCOUNTY 9} Force Majeure ,. ;~i,~-'.:; a) Suspension of I'erfarmance: The `perfolfnance of its duties and obligations hereunder by either party shall be suspended: to the extent that such performance, in whole or in part, shall be render3;???prr:~c~abl~,l~y~~'orce Majeure. b) Definition: Force Majeilre -For purposes herein, Force Majeure shall be termed as any event or occurrence of any nature or kind in respect to the duties herein that is beyond the control of and occurs without the negligence of the party invoking the same, including without limitation: acts of God or of a public enemy, acts of government or governmental authority in either its sovereign or contractual capacity, wars, riots, fires, floods, explosions, epidemics, boycotts, excessive fi~el prices, blackouts, strikes, labor disputes, equipment breakdowns, and any transportation problem directly affecting or inhibiting pickups. e} Notice: In the event that either party hereto determines that a Force majeure has occurt•ed, or its is likely to occur, said patty shall promptly furnish to the other party notice in writing of such Force Majeure, setting forth the nature of such problem, the anticipated effect thereof on said party's performance hereunder and when normal performance may be expected. In the event of excessive filer prices of over the road diesel. Contractor and County will negotiate satisfactory terms for both parties involved. ~~~ . d) No Um•easonable Delay: Any party~hereto whose performance hereunder is delayed or prevented by a factory 6~~oz'c~~l~I~jEUs;:,ajid said party subsequently invokes force Majeure, shall take all reasonahle step$ to ie~ume, with the least possible delay, compliance with its obligations hereunder, provided that said party shall not be required to settle any strike or labor dispute on terms not acceptable to it. 10) Representations 10.1) The Contractor represents, warrants and covenants to County that: a) It is an entity duly organized, validly existing and in good standing under the laws of the State of North Carolina, and is duly and validly qualified to conduct business and is in good standing in all jurisdictions in which such qualification is necessary. b) The execution, delivery and perfoimarice of this Contract have been duly and validly authorized by all corporate action required to be taken and will not result in a breach of, constitute a Default under, or violate the terms of Contractor's organizational agreement, or any rule, regulation, judgment, decree, order, or agreement to which Contractor is a parry or by which it may be bour~;t ~ =~~ ;- :,~. Attachment number 1 F-10 Page 136