AG19870908 - Laserfiche WebLink

Home Browse Search

2.2.3, Through the observations by such Field Representatives, ENGINEER shall endeavor to provide further protection for the OWNER against defects and deficiencies in the Work, but the furnishing of Such PROJECT representation shall not modify the rights, responsibilities or obligations of E~GINEER as described in Construction Phase - Administration of the Construction Contract. 2.3 Other Additional Services. 2.3,1. Services r~sulting from significant changes in the general scope, extent or character of the PROJECT and revising previously accepted design documents or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or oraers enacted subsequent to the preparation of such documents, or are due to any other causes beyond ENGINEER's control. 2.3.2. Providing any type of property surveys or related engineering services needed for the transfer of interests in real property. 2.3.3. Assistance in connection with bid protests, rebiUding or renegotiating contracts for construction, materials, equipment or services. 2.3.4. Preparing to serve or serving as a consultant or witness for OWNER in any litigation, arbitration or other legal or administrative proceeding involving the PROJECT. 2.3.5. Additional or extended services during construction made necessary by (1) work damaged by fire or other cause ~uring construction, (2) a significant amount of defective or neglected work of any Contractor, {3) acceleration of the progress schedule involving services beyond normal working hours, (4) default by any Contractor, and (5) failure of Contractor to complete the Work within the time stipulated in the Contract Documents. 2.3.6. Preparation of operating, maintenance and staffing manuals and assisting OWNER in training OWNER's staff to operate and maintain the PROJECT. SECT)ON 3 - OWNER'S RESPONSIBILITIES OWNER shall do the following in a timely manner so as not to delay the services of ENGINEER. 3.1. Designate in writing a person to act as OWNER's representative with respect to the services to be rendered under this Agreement. Such person shall have complete authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to ENGINEER's services for the PROJECT. 3.2. Assist ENGINEER by placing at disposal all available information pertinent to the PROJECT including previous reports and any other data relative to design or construction of the PROJECT. -6-