AG 2002 07 22 (Regular) - Laserfiche WebLink

Home Browse Search

3.3.1 The services deacribed in this Paragraph 3.3 are not included in Basic Seaxicss unless so identified in Article 14, and they shall be paid for bythe Owner.as provided in this Part 2 Agreement, .in addition to the compen.,~ion for Basic Services. Thc services described in this Paragraph 3.3 shall bc provided only if authorized or confimaed in writing by the 3,3.2 Making revisions in dmwir~, specifications, and other documents or electronic da~_ when such mvisiom are required by the enactment or revisionof ~tes, laws or resulations subsequent to the preparation of such documents or electronic 3.3.3 Providing consultalion concerning replacement of Work damaged by fire or.other-cause .during construction, and furnishing services required in connection with the replacement of such Work. 3.3.4 Providing services in connection with a public hearing, arbita'ation proceeding or legal proeeed'm~ except v~here the Design/Builder.is a party thereto. 3,3.$ Providing coordination of eonsmletion performed by the Owner's own forces or separate contractors employed by the Owner, and coordination of services required in connection with construction performed and equipment supplied by the Owner. 3.3.6 Preparing a set of reproducible r~cord documents ~ el~tronk data showing siilniftemat daanges in the Work made during construction. 3.3.7 Providing assistance in the utilization of equipment or systems such as preparation of operation and maintenance manuals, ~ personnel 'for operation and maintenance, -and consultation .durin~ -operation. ARTIOL~ 4 ~HIVIE 4.1 Unless otherwise indicated, the Owner and the Dcsigri/Builder.shall perform fl~eir mspactive obligations .as expeditiously as is consistent with reasonable skill and care and'the orderly progress of the Project. 4.2 Time limits stated in 'the Contract Documents are of the essence. The Work to be performed under this Part 2 Agreement shall commence upon receipt of a notice to proceed unless otherwise agreed and, subject to authorized Modificatior~, Substantial Completion sha!l be achieved on or before the date established in Article 14. See Project Schedule. Exhibit B. attached and incorporated herein. The Desigr~Builder shall achieve Substantial Completion of the entire Work not later than June 2, 2003. 4.3 Substantial Completion is the stage in the progress the Work when the Work or designated portion thereof is suffieianfly complete in accordance with the Contract Documents so the Owner canoecupy or utilize the Work for its intended u~e. The. Owners receiving a temporary Certificate of Occupancy_ is a condition precedent to the Desi_mffBuildefs achieving_ Substantial Completion and at the Owner's reasonable discretion_ the Owner's receiving a Final Certificate of Oc~m_ranc_.v ma:v be a condition precedent to the Design/Builders achieving_ substantial completion, 4.4 Based on the Design/Builder's .Proposal, a CPM construction schedule utilizing_ ~ecedent di~_~ ~ critical ~shall be provided consistent with Paragraph 4.2 above. 4.S .If the Design/Builder is delayed at any time in the progress of the Work by an act or neglect of the Owner, Owner's employees, or separate contractors employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, adverse weather conditions not reasonably anticipatable, unavoidable casualties or other causes beyond the Design/Builder's control, or by delay authorized by the Owner pending arbitration, or by other cause, s ~vhi~ the Ovmer sad Design/Builder agree may ju.~ fy delay, and such delays are on the critical path and are not concurrent with any other Desi_~,n/Builder-cal]sed delay, thea the Contract Tim~ shall be reasonably e, xleaded by Cl~i~e Order. fflsert W: 4.5. I if adverse weather conditions are the 'b'~iS for a Claim for additional time. such Claim shall be documented by data substantiatir~_ that weather conditions were abnormal for The period of time. could not have been reasonably anticipated and had an adverse effect on the scheduled constructior~ Acceptable da~a for substantiating_ a claim .for.addit;ionat .time ~lue .to .abnormal weather conditions wilt be the records of.the National Oceano_m,aphic-and Atmospheric Admi~sia'a~ion .(~OAA) for the ~m~or 5 .,,~ars. In .the absence .of NOAA-rec~ds for the Pro. iect site. local official records will be acceptable. Insert X: 4.6 Notwithstandir~_ an_v 1 _angu~_e in the Cnntract Documents to the contrary_, if the Desi_ma/Builder is dela_ved ~ the prc~_ ess .of lbo. g/ork_by_an_v.aeI or n~_ie~.t of_the Owner_ any of.its employees.or .~ents. or any separate contractor employed by the Owner. or a chan_~e order, the Desi_on/Builder shall be _mmated a time extension and additional monetary · compensation for costs inetuding extended 'general conditions. related direct costs and claims by third parties. For all other